LA Excavation, Inc – Terms and Conditions

Effective Date: July 1, 2025

Welcome to LA Excavation. By submitting an online form through our website, or any affiliated digital platform, you agree to the following terms and conditions.

1. General Information – LA Excavation, Inc. is a Maine-based excavation company located in Auburn, ME, offering residential and commercial excavation services, including but not limited to demolition services, foundation installation, septic system installation. These Terms and Conditions apply to all users who submit forms requesting general correspondence, quotes, consultations, or service inquiries.

2. Acceptance of Terms – By completing and submitting any form on our platform, you acknowledge that:

• You are at least 18 years of age or have permission from a legal guardian.
• The information provided is truthful and accurate.
• You have read and agreed to these Terms and Conditions.

3. Use of Personal Information – Your submitted information will be used solely for the purpose of:

• Contacting you regarding your service inquiry
• Providing estimates or scheduling consultations.
• Sending occasional service updates or promotional messages (you may opt-out anytime).

We respect your privacy and will not sell or share your data with third parties except where legally required. For more details, see our Privacy Policy.

4. Quotes and Estimates

• All quotes provided through form submissions are preliminary and non-binding.
• Final pricing will be confirmed after an on-site evaluation.
• Estimates are valid for 30 days from the date issued unless otherwise stated.

5. Service Availability

All services are subject to crew availability, site conditions, and weather-related delays.
LA Excavation, Inc. reserves the right to decline service requests based on project type, location, or other constraints.

6. Communication

By submitting a form, you consent to receive communication from LA Excavation, Inc. via:

• Phone calls
• SMS/text messages
• Emails
  Standard message and data rates may apply. You may opt out by replying “STOP” to text messages or emailing us at [your email here].

7. Client Responsibilities – You agree to:

• Provide accurate details about the property and project scope.
• Ensure access to the worksite during scheduled evaluations or services.
• Obtain any required permits unless specified otherwise in writing.

8. Liability Disclaimer – LA Excavation is not liable for:

• Delays caused by weather, utility company interference, or permit issues.
• Damage to underground utilities not properly marked by the property owner or Dig Safe.
• Site complications caused by unreported or unknown property features.

9. Intellectual Property

All content on our website and forms (including logos, service descriptions, and designs) is the property of LA Excavation, Inc. and may not be copied, distributed, or reused without written consent.

10. Modifications to Terms

We reserve the right to update or change these Terms and Conditions at any time. Continued use of our forms constitutes acceptance of any revised terms.

11. Governing Law

These Terms and Conditions are governed by the laws of the State of Maine. Any disputes shall be resolved in the courts of Androscoggin County, Maine.

12. Contact Us – For any questions or concerns, please contact:

LA Excavation, Inc.
144 Eastman Ln.
Auburn, ME 04210
Phone: 1(207)576-3047
Email: laexcavationinc@yahoo.com